In these conditions “the Seller” means Rethync Ltd, Unit 12 West Moor Park NetworkCentre, Yorkshire Way, Armthorpe, Doncaster, DN3 3GW (“the Registered Office”), “the Premises” means the Registered Office or any other property owned, leased, rented or otherwise used by the Seller during its normal course of business and “the Buyer” means any person placing an order with the Seller for the supply and/or installation of goods or the provision of services (“Goods”).



Quotations do not constitute an offer by the Seller to supply the Goods or carry out the work referred to therein and no order placed in response to a quotation will be binding unless accepted by the Seller in writing. All such acceptances by the Seller will be subject to availability of the necessary materials and to the Seller being able to obtain any necessary authorisation and or licences and the same remaining valid.


  1. The Seller shall endeavour to maintain prices given on quotation or acceptance of order but reserves the right to vary its prices without notice to take account of changes in the Seller’s costs and all Goods will be charged at prices ruling at the time of delivery.

  2. Where the contract includes installation, the price stated assumes normal excavation conditions. Where the Seller encounters physical conditions (other than weather) or artificial obstructions which conditions or obstructions the Seller considers could not have been foreseen, the Seller shall take such action as is necessary and if in taking such action incurs extra costs such costs shall be for the account of the Buyer.

  3. The price stated in the contract allows for carriage of materials within ten metres of a metalled road. Any additional carriage shall be added to the price.

  4. Where the price for the Goods is varied in accordance with this Condition 3 the price as varied shall be binding on both parties and shall not give either party any option of cancellation.

  5. There shall be added to the price for the Goods any value added tax and any other tax or duty relating to the manufacture, transportation, export, import, sale or delivery of the Goods (whether initially charged on or payable by the Seller or the Buyer).

  6. All prices are quoted in pounds sterling unless otherwise specified and all payments must be made in pounds sterling unless otherwise expressly agreed.



The Buyer shall be responsible for the true and proper setting out of the Works and for the correctness of the position, levels, dimensions and alignment of all parts of the Works. If at any time during the progress of the Works any error shall appear in the position levels, dimensions or alignment of any part of the Works the Buyer on being required so to do by the Seller shall at his own cost rectify such error.



  1. Prices quoted are net of VAT.

  2. Subject to credit approval, all accounts are due on a strict net monthly account basis unless otherwise agreed.

  3. Where the order is delivered in multiple consignments, each consignment will be invoiced as despatched and each month’s invoice will be treated as a separate account and be payable accordingly.

  4. If completion of the contract is delayed due to site or other circumstances outside the control of the Seller, the Seller shall submit an invoice for the value of the contract completed as at the invoice date which is to be treated as a separate account and be payable accordingly.

  5. Failure to pay for any Goods or for any delivery or instalment shall entitle the Seller to suspend further deliveries and work, both on the same order and on any other order from the Buyer, without prejudice to any other right the Seller may have.

  6. The Seller also reserves the right, under the Late Payment of Commercial Debts (Interest) Act 1998, to charge interest on overdue accounts at the rate of 8% per annum over the Bank of England base rate at the preceding 31 December or 30 June.

  7. The Seller reserves the right, where genuine doubts arise as to a Buyer's financial position or in the case of failure to pay for any Goods or any delivery or instalment as aforesaid, to suspend delivery of any order or any part or instalment without liability until payment or satisfactory security for payment has been provided



  1. The delivery or performance dates specified in the contract are approximate only and, unless otherwise expressly stated, time is not of the essence for delivery.

  2. The Seller will not be liable in any circumstances for the consequences of any delay in delivery or failure to deliver if the duration of the delay is not substantial or if the delay or failure is due to act of God, fire, inclement or exceptional weather conditions, industrial action (whether at the Seller’s premises or elsewhere), hostilities, breakdowns, shortage of labour, materials, power or other supplies, late delivery or performance or non-delivery or non-performance by suppliers or sub-contractors, governmental order or intervention (whether or not having the force of law) export restrictions (whether or not existing at the date of the contract) or any other cause whatever beyond the Seller’s control or of an unexpected or exceptional nature.

  3. No delay shall entitle the Buyer to reject any delivery or any further instalment or part of the order or any other order from the Buyer or to repudiate the contract or the order.

  4. The Seller cannot undertake to meet any schedule of the Buyer’s requirements supplied after the date of the contract and will have no liability whatever for delay in meeting or failure to meet all or any of such requirements (howsoever such failure or delay may arise) unless and to the extent that the Seller expressly agrees to meet such requirements, in which event paragraph ii) of this Condition shall apply.



If for any reason the Buyer is unable to accept delivery of the Goods when the Goods are due and ready for delivery the Seller may arrange storage of the Goods and the Buyer shall be liable to the Seller for the reasonable costs (including insurance) of such storage. This provision is without prejudice to any other right which the Seller may have in respect of the Buyer's failure to take delivery of the Goods or to pay for them in accordance with the contract.


  1. The risk in the Goods shall pass to the Buyer:

    1. when the Goods are delivered at the destination specified in an order.

    2. if the Goods are appropriated to the Buyer but kept at the supplier’s premises upon collection of the Goods by the buyer or upon the expiry of 7 days from the Seller's written notice to the Buyer that such Goods are ready for delivery whichever is the earlier.

  2. Notwithstanding sub-clause (a) above, absolute property in and title to the Goods shall remain vested in the Seller and the Buyer shall keep the Goods as bailee and trustee for the Seller (returning the same to the Seller upon request) until the price thereof has been paid in full together with any interest and all other sums due in respect thereof from the Buyer in accordance with the order.

  3. If the Buyer

    1. manufactures another article or articles from the Goods with or without the addition of other materials and/or

    2. mixes the Goods in any way whatsoever with other materials and/or

    3. incorporates the Goods into any other article as a component part, the property in the products of such manufacture, mixing or incorporation ("the Products") shall be transferred to the Seller at any time of such manufacture, mixing or incorporation and the Buyer shall keep the Products as bailee and trustee for the Seller until the price of the Goods comprised therein has been paid in full together with any interest and all other sums due in respect thereof from the Buyer.

  4. Pending payment for Goods as aforesaid the Buyer shall (subject to sub clause (c) above) store them separately and in such a way that they can be identified as the property of the Seller, and the Seller shall be entitled to direct the Buyer not to resell the same or remove them from where they are located without consent. Any Goods in the Buyer's possession shall be presumed not to have been paid for unless the Buyer can prove otherwise and the Seller shall have the right to appropriate any payment made by the Buyer to any invoice or invoices (whether or not due at the time of payment) in the Seller's absolute discretion.

  5. If pending payment for Goods as aforesaid the Buyer shall sell or otherwise dispose of the Goods or Products or make any insurance claim in respect thereof, the Buyer shall not give any warranties or incur any liabilities on behalf of the Seller and the proceeds of any such sale or other disposition (or claim hereto) or any such insurance proceeds (or claim thereto) shall belong to the Seller and be held by the Buyer as trust funds to the extent of all sums due to the Seller in respect of such Goods, and the Buyer shall pay such proceeds into separate account.

  6. At any time prior to full payment (whether or not payment is then overdue) the Seller may (without prejudice to any of its other rights) retake possession of the Goods or any part thereof and may enter on the Buyer’s premises by its employees or agents for that purpose or for the purpose of ascertaining whether the Buyer is complying with the provisions of this condition 8.

  7. Any Goods repossessed by the Seller may be resold on such terms as the Seller may determine and the Buyer shall remain liable to the Seller for the difference between the net proceeds of such resale and all outstanding sums due to the Seller in respect of such Goods and for all costs and expenses incurred by the Seller in repossessing, storing and reselling the same.

  8. Nothing in this condition shall give the Buyer any right to return Goods sold by the Seller and the Seller may sue the Buyer for the price when due (without prejudice to its other rights) notwithstanding that property therein may not have passed to the Buyer.

  9. The Buyer’s rights to use the Goods or to sell them prior to full payment may be terminated forthwith by written notice given by the Seller to the Buyer and shall automatically terminate with or without such notice if a receiver is appointed over any of the assets or the undertaking of the Buyer or a winding up order is made against the Buyer or the Buyer goes into voluntary liquidation (otherwise than for the purpose of solvent reconstruction or amalgamation) or calls a meeting of or makes any arrangement or composition with its creditors generally or commits any act of bankruptcy or allows execution or distress to be levied against its goods and in the event of a Receiver or Liquidator of the Buyer being appointed, such Receiver or Liquidator shall pay into a separate bank account any sums received from third parties in respect of sales to them of Goods or Products by the Buyer up to the amount of any indebtedness of the Buyer to the Seller for the sole benefit of the Seller.



  1. The Seller Warrants that it will (at the Seller’s choice) either repair or replace, or refund the full purchase price of any Goods or workmanship which is found within a period of 1 month from installation or despatch of such Goods from the Premises ("the warranty period") to be defective or not in accordance with the contract or any express description or representation given or made on behalf of the Seller in respect of the Goods or workmanship. The Buyer’s remedies in respect of any claim under the foregoing express warranty or any condition or warranty implied by law or any other claim in respect of the Goods or any workmanship in relation thereto or workmanship (whether or not involving negligence on the part of the Seller) shall in all cases be limited to repair or replacement of the Goods or to refund of the purchase price of the Goods as aforesaid and any condition or warranty implied by law shall cease to apply after the expiry of the warranty period: and the Seller shall not in any circumstances be liable for any damages, compensation, costs, expenses, losses or other liabilities, whether direct or consequential, and any other remedy which would otherwise be available in law is hereby excluded except to the extent that such exclusion is prohibited by any rule of law. A claim in respect of any defect or failure to comply with the specification or order or in respect of any delivery or instalment of an order or any part thereof shall not entitle the Buyer to cancel or refuse delivery of or payment for any other order, delivery or instalment or any part of the same order, delivery or instalment. The Seller will require a reasonable period of time to carry out any repairs or replacements.

  2. If any alteration or modification is made to the Goods without the Seller's written authorisation, then the Seller shall be under no obligation to repair, replace or refund the full purchase price of any Goods which are found within the warranty period to be defective or not in accordance with the contract or any express description or representation given or made on behalf of the Seller in respect of the Goods.


The Buyer agrees upon demand to indemnify the Seller against all losses, damage, injury, costs and expenses of whatever nature suffered by the Seller to the extent that the same are caused by or related to:

  1. defective materials or products supplied by the Buyer to the Seller and incorporated by the Seller in goods produced by the Seller for the Buyer; or

  2. the improper incorporation, assembly, use, processing, storage or handling of Goods by the Buyer.

  3. the failure of the Buyer to notify the Seller of the nature of the ground and subsoil, the form and nature of the site, and in general to provide the Seller all necessary information (subject as above mentioned) as to risk contingencies and all other circumstances influencing the Seller.



Any extra work, requirement or modifications (including but not limited to foundation work) in relation to the Goods or their installation which is expressly specified in the contract or which is expressly excluded by these conditions and which the Buyer requests shall, if the Seller is able and willing to agree thereto, be charged extra (including an appropriate allowance for profit) to the extent that such extra work requirement of modification increases the cost to the Seller of performance of the contract, and the Seller shall be allowed a reasonable extension or postponement of performance or delivery dates required to comply with any such request.


  1. The Seller shall only be obliged to carry out tests which are specified in the contract, and reasonable excesses and deficiencies thereof shall be accepted by the Buyer who shall not be entitled to reject any Goods on the ground that they are not precisely as specified. Tests and inspections shall take place under the Seller’s standard testing arrangements. Any additional testing which the Seller expressly agrees to carry out for the Buyer shall be charged extra to the Buyer and shall be undertaken subject to those conditions. Where the Buyer requires to be present at any tests or inspections the Seller shall give the Buyer as much notice as is reasonably possible of the date and time such tests and inspections shall take place and if the Buyer or any third party fails to attend such tests and inspections the Seller shall be permitted to undertake such tests and inspections without liability to the Buyer and shall notify the results thereof to the Buyer who shall not be entitled to request further tests and inspections.

  2. If any special arrangements must be made to facilitate the requirements of the Buyer, then at the discretion of the Seller, a charge may be made for all costs incurred in facilitating the inspection of the goods.


  1. The Seller is entitled to assume that all drawings, descriptions, specifications and other information supplied by the Buyer to the Seller, whether written or verbal, are in all respects complete accurate and entirely suitable for the Buyer’s requirements.

  2. Unless otherwise expressly agreed, the Seller shall have no responsibility for the performance, suitability or durability or any Goods or any materials or workmanship comprised therein to the extent that the same is manufactured in accordance with the buyer’s designs, drawings, standards or specifications.


  1. Any drawings, specifications or other technical information supplied to the Buyer by the Seller in connection with the contract are provided on the express understanding that the Buyer will not give loan, exhibit or sell such drawings, specifications or technical information to any third party and that the Buyer will not use them in any way except in connection with the Goods or services provided hereunder. The copyright in all documents provided by the Seller will remain vested in the Seller.

  2. The Buyer shall indemnify the Seller against all actions, costs (including the cost of defending any legal proceedings), claims, proceedings, accounts and damages in respect of any infringement or alleged infringement of any patent, registered design, copyright, trademark or other industrial or intellectual property rights resulting from compliance by the Seller with the Buyer’s specific requirements, designs or specifications.



The risk in the Goods passes to the Buyer when specified by condition 8 above, and the Seller accepts no responsibility for any damage, shortage or loss in transit thereafter. Claims for any damage, shortage or loss in transit should be notified immediately by telephone or email to the Seller.


The Seller reserves the right to sub-contract the whole or any part of the contract.


No forbearance or indulgence by the Seller shown or granted to the Buyer whether in respect of these conditions or otherwise shall in any way affect or prejudice the rights of the Seller against the Buyer or be regarded as a waiver of any of these conditions.


The contract shall in all respects be governed by and construed in accordance with the law of England & Wales and the Buyer hereby submits to the exclusive jurisdiction of the Courts of England & Wales.